ALLIES & ROSS MANAGEMENT AND DEVELOPMENT CORPORATION INVITATIONS FOR BIDS (IFB) FOR Manchester Home Inspections Rebid ARMDC IFB #2019-27-REBID The Allies & Ross Management and Development Corporation (ARMDC) hereby request bids from qualified Firms or Individuals capable of providing the following service(s): Manchester Home Inspections The documents will be available no later than June 3, 2019 and signed, sealed proposals will be accepted until 10:00 a.m., June 28, 2019 at which time they will be Time and Date Stamped at 100 Ross Street, 2nd Floor, Suite 200, Pittsburgh, PA 15219. Parties or individuals interested may obtain information from: Mr. Kim Detrick Procurement Director/Chief Contracting Officer Housing Authority of the City of Pittsburgh Procurement Department 2nd Floor, Suite 200 100 Ross Street Pittsburgh, PA 15219 412-456-5116, Option 1 or by visiting the Business Opportunities section of www.hacp.org A pre bid meeting will be held: Housing Authority of the City of Pittsburgh Procurement Department 100 Ross Street, 2nd Floor, Conference Room Pittsburgh, PA 15219 June 13, 2019 10:00 A.M. The Allies & Ross Management and Development Corporation strongly encourages certified minority business enterprises and women business enterprises to respond to this solicitation. ARMDC has revised their website. As part of those revisions, vendors must now register and log-in, in order to view and download IFB/RFPs documentation. Caster D. Binion, President & CEO Allies & Ross Management and Development Corporation ARMDC & HACP conduct business in accordance with all federal, state, and local civil rights laws, including but not limited to Title VII, the Fair Housing Act, Section 504 of the Rehabilitation Act of 1973, the Americans with Disabilities Act, The PA Human Relations Act, etc. and does not discriminate against any individuals protected by these statutes.
↧
ALLIES & ROSS MANAGEMENT AND D...
↧
INVITATION TO BIDDERS THE PITT...
INVITATION TO BIDDERS THE PITTSBURGH WATER AND SEWER AUTHORITY ADVERTISEMENT SEPARATE and SEALED BIDS for the following solicitation, will be received by the Office of Procurement, Pittsburgh Water and Sewer Authority, 1200 Penn Ave., Second Floor, Pittsburgh, PA 15222, until 2:00 PM Prevailing Time June 27, 2019. INVITATIONS FOR BIDS (IFB) FOR THE PRESSURE MONITOR LINE INSTALLATION CONTRACT PWSA PROJECT NO. 2017-325-114-1 Work of the Contract includes the installation of service lines and meter pits for the connection of pressure monitors (by others) of the public water system, including water mains, service connections, meter crocks, and hydrants as required or directed. All bids must be submitted in accordance with the solicitation that can be obtained by sending an e-mail to procurement@pgh2o.com. There will be no charge for the solicitation, as it will be sent via e-mail. All questions relating to the solicitation itself shall be to Nicole Dickun, Procurement Manager, via e-mail: ndickun@pgh2o.com, no later than June 20, 2019. A Mandatory Pre-Bid Meeting will be held on June 12, 2019, 10:00 a.m. prevailing Time in the Authority's conference room located at 1200 Penn Ave., Pittsburgh, PA. The purpose of this meeting is to give an overview of the contract requirements and to allow Bidders to ask questions. Bids must be accompanied by a Bid Bond in the amount of Ten Percent (10%) of the bid for the project under construction. Said Bond shall be duly and legally executed with a Surety or Trust Company which has complied with City Ordinances/Resolutions relating thereto. A Performance Bond and Labor and Material Bond in the amount of 100% of the contract value for each awarded project will be required after award. The Contractor must assure that employees and applicants for employment are not discriminated against because of their race, color, religion, sexual preference, sex, or national origin. The bidders will be required to submit the package of certifications included with the contract documents relating to Equal Employment Opportunity. The Authority reserves the right to withhold the award of the Contract for a period of 60 days after the opening of the bids. The Authority reserves the right to reject any or all proposals, and to waive any informality or minor irregularity in any bid or bids. The Authority also retains the right to investigate the qualifications of bidders prior to any award and to award contracts only to contractors who, in the sole judgment of the Pittsburgh Water and Sewer Authority are qualified and equipped to properly execute the specified work. ROBERT A. WEIMAR, EXECUTIVE DIRECTOR THE PITTSBURGH WATER AND SEWER AUTHORITY
↧
↧
BETHEL PARK SCHOOL DISTRICT NO...
BETHEL PARK SCHOOL DISTRICT NOTICE OF SPECIAL MEETING The Board of School Directors of the Bethel Park School District announces the follow- ing meeting that will be held in the Community Room of the Administration Building, 301 Church Road, Bethel Park, PA 15102. Special Meeting for General Purposes on Wed- nesday, June 5, 2019 at 7:00 PM.
↧
ADVERTISEMENT SEALED PROPOSALS...
ADVERTISEMENT Sealed proposals will be received by the Township of Pine, 230 Pearce Mill Road, Wexford, Pennsylvania 15090 until 11:00 AM and opened at 11:00 AM on June 12, 2019 for the following: CONTRACT NO. 19-SW01 2019 PEDESTRIAN IMPROVEMENTS The scope of work generally consists of approximately 1,800 square feet of concrete sidewalk construction; 900 square feet of segmental retaining wall; 2 ADA ramps; 250 square yards bituminous roadway / driveway adjustment; earthwork and grading; and all necessary appurtenances and restoration for said pedestrian improvement construction along Swinderman Road. Bid Documents are being distributed by F. L. Haus Company, 921 Ridge Avenue, Pittsburgh, PA 15212. All bidders are required to buy the full set of drawings and specifications (as applicable) for a non-refundable deposit of $75.00 from F. L. Haus Company at www.flhausplanroom.com. Any questions on ordering the bid documents are to be directed to Clem Sutton at 412-231-7700 or csutton@flhaus.com. Any technical questions regarding the bid documents are to be directed to Lennon, Smith, Souleret Engineering, Inc. (412-264-4400, Ext. 212). Pennsylvania prevailing wage rates apply. Proposals must be upon the forms furnished by the Township. The bid must be accompanied by a certified check or bid bond in the amount of ten percent (10%) of the bid, made payable to the Township of Pine to guarantee the bidder's entrance into the contract if given the award. No bid bond shall be waived or returned because the Bidder has failed to or cannot comply with any requirements as set forth in the plans, specifications, or any applicable statutes of the Commonwealth of Pennsylvania or any applicable municipal ordinances. The Township reserves the right to reject any or all proposals and to waive any informalities in the bidding. No bid may be withdrawn for ninety (90) calendar days after the scheduled time for receipt of bids. Attention is directed to the fact that procurement is subject to all requirements of the Pennsylvania "Steel Products Procurement Act, Act No. 1978-3"; and for Contract value exceeding $25,000, the Pennsylvania Prevailing Wage Act (Act of 1961 P.L. 987), and The Public Works Employment Verification Act (July 2012) apply. The Township shall (a) award the construction contract to the lowest responsible bidder therefore, or (b) reject all bids received within ninety (90) days of the date of bid opening; provided, however, that the Township may, in its sole discretion, delay such award or rejection for up to one hundred twenty (120) days from the bid opening date until the Township has received all required approvals from other governmental agencies. Bidders on this work will be required to comply with Title VI of the Civil Rights Act of 1964. TOWNSHIP OF PINE Scott D. Anderson, Manager
↧
PUBLIC NOTICE ALLEGHENY COUNTY...
PUBLIC NOTICE ALLEGHENY COUNTY SANITARY AUTHORITY The Green Committee of the Allegheny County Sanitary Authority will hold a special meeting for general purposes on Tuesday, June 11, 2019 at 2:00 p.m. prevailing time in the Trefz Board Room at its offices located at 3300 Preble Avenue, Pittsburgh, Pennsylvania 15233. The public is invited to attend and participate.
↧
↧
ADVERTISEMENT SEALED PROPOSALS...
ADVERTISEMENT Sealed proposals will be received by the Borough of Pleasant Hills of Allegheny County, Pennsylvania at the Borough office located at 410 East Bruceton Road, Pittsburgh, Pennsylvania 15236 until 4:00 PM prevailing time on June 17, 2019 for: CONTRACT NO. 18-S1 TERENCE DRIVE STORM SEWER EXTENSION The scope of work includes the complete installation of approximately 650 linear feet of new storm sewer, catch basins, manholes, connection to the existing storm system, and all necessary appurtenances and restoration for said construction. All work shall be constructed according to the Contract Drawings and Specifications which are on file at the office of the Owner and Lennon, Smith, Souleret Engineering, Inc., 846 Fourth Avenue, Coraopolis, Pennsylvania 15108-1522. Bids will be publicly opened and read aloud approximately at 7:30 PM on June 17, 2019 at the Borough Office located at 410 East Bruceton Road, Pittsburgh, Pennsylvania 15236. Bid Documents are being distributed by F. L. Haus Company, 921 Ridge Avenue, Pittsburgh, PA 15212. All bidders are required to buy the full set of drawings and specifications for a non-refundable deposit of $100.00 from F. L. Haus Company at www.flhausplanroom.com. Any questions on ordering the bid documents are to be directed to Clem Sutton at 412-231-7700 or csutton@flhaus.com. Any technical questions regarding the bid documents are to be directed to Lennon, Smith, Souleret Engineering, Inc. (412-264-4400, Ext. 212). Pennsylvania prevailing wage rates apply. Proposals must be upon the forms furnished by the Borough. The bid must be accompanied by a certified check or bid bond in the amount of ten percent (10%) of the bid, made payable to the Borough to guarantee the bidder's entrance into the contract if given the award. No bid bond shall be waived or returned because the Bidder has failed to or cannot comply with any requirements as set forth in the plans, specifications, or any applicable statutes of the State of Pennsylvania or any applicable municipal ordinances. The Borough reserves the right to reject any or all proposals and to waive any informalities in the bidding. No bid may be withdrawn for ninety (90) calendar days after the scheduled time for receipt of bids. Attention is directed to the fact that procurement is subject to all requirements of the Pennsylvania Steel Products Procurement Act, Act No. 1978-3; and for Contract value exceeding $25,000, the Pennsylvania Prevailing Wage Act (Act of 1961 P.L. 987), and The Public Works Employment Verification Act (July 2012) apply. The Borough shall (a) award the construction contract to the lowest responsible bidder therefore, or (b) reject all bids received within ninety (90) days of the date of bid opening; provided, however, that the Borough may, in its sole discretion, delay such award or rejection for up to one hundred twenty (120) days from the bid opening date until the Borough has received all required approvals from other governmental agencies. Bidders on this work will be required to comply with Title VI of the Civil Rights Act of 1964. BOROUGH OF PLEASANT HILLS Kelly J. Theiss, Borough Manager
↧
PUBLIC NOTICE IS HEREBY GIVEN ...
Public notice is hereby given that property placed in storage by the following persons at the following locations will be sold via public sale to satisfy Guardian Storage liens for unpaid rent and other charges. Bidding for property of persons renting space at the following locations will be held online at www.selfstorageauction.com beginning June 3, 2019 and ending on June 14, 2019 at 10:00 AM, at which time a high bidder will be determined. 5873 Centre Ave Pittsburgh, PA 15206: Unit #4102 Terra Holloway, Unit #4505 Rachel Farley, Unit #5119 Kevin Jones, Unit #5703 Christian Jackman, Unit #6401 Patricia Rodgers, Unit #7108 Ronald Shealey 2839 Liberty Ave, Pittsburgh, PA 15222: Unit #2212 Renae Greenman, Unit #2804 Seas Kim, Unit #3102 Seas Kim, Unit #3316 Jamaree Murray, Unit #4310 Irvin Summers, Unit #4607 Robert Adams, Unit #4909 Christopher Brown, Unit #4910 Pamela Mazurek, Unit #4913 Josephin Felton, Unit #5127 Felicia Davis, Unit #5310 James Reid, Unit #5910 Sarah Brown 1300 Lebanon Church Road, Pittsburgh, PA 15236: Unit #12101 Marie Morgart, Unit #12110 Lori Rechtorik, Unit #12504 Pam Novicki, Unit #32312 Jessica Oskin 750 South Millvale Ave, Pittsburgh PA 15213: Unit #303 Tanika Cabbagestalk, Unit #6517 Arika Diggs 1002 East Waterfront Drive, Munhall, PA 15120: Unit #1323 Earl Grier, Unit #2303 Joyce Walker, Unit #3117 Eliza Elquali, Unit #3311 Tamiah Cain, Unit #3320 Katisha Correll, Unit #3743 Whitney Melvin, Unit #3750 Lawrence Walker, Unit #3754 Matthew Brown, Unit #3807 Boris Langer, Unit #3818 Eric Duncan
↧
AFANDOLO, TONOU MAWUFIA; ALABI...
Afandolo, Tonou Mawufia; Alabi, Loveth O, Pittsburgh Albert, Samuel Bernard, Arlington, VA; Biernesser, Samantha, Cheswick Alhussain, Wasel, Morgantown, WV; Abdullah, Fatema Alzhraa, State College Brower, Kevin Charles; Ceric, Sandra, Abingdon, MD Castaneda Perez, Adelina; Justo Perez, Amado, Braddock Channarasappa, Anirudh; Akubathini, Keerthi, Columbus, OH Coon, Nikki Leah, Smicksburg; Kostial, Aaron Joseph, Pittsburgh Coulverson, Tayla; Gilbert Sr., Nyeem Rashaud, Pittsburgh Douglas, Melinda Mae; Suttor, Joshua Thomas, Pittsburgh Evans, Anya D; Brown, Marvin Anthony, Verona Evans, Elizabeth Robb; Sheedy, Edward Waterman, Pittsburgh Farley, Colin; Smucker, Emily, Pittsburgh Fontanesi, Michael Thomas; Hardner, Sarah Elizabeth, Carnegie Gilberti III, Frank Francis; Brown, Malinda Kay, Pittsburgh Gilfillan, Matthew R; Buzzelli, Brittany M, Oakdale Grinberg, Yevgeniy; Compton, Paige Erin, Pittsburgh Hammer, Karan Patricia; Morris, John Edward, Pittsburgh Hruska, Jacqueline Elizabeth; Novak, Jeffrey Conrad, Brooklyn, NY Humphries, Latisha; Winters, Brandon, Pittsburgh Johns, Sandra Jean; Reidinger, Michael J, Pittsburgh Jordan, Ashley Rene; Zankel Jr., Ross Alan, Crescent Kimmel, Kimberly Jane; Bombich, Stephen John, Pittsburgh King, Avery Noah; Warne, Emily Michele, Bridgeville King, Keegan; Suder, Jessica Aryn, Wexford Kolat, Nicholas John; Hudak, Natalie Marie, Bridgeville Kurapati, Nikhil T, Pittsburgh; Aemul, Harika, Coconut Creek, FL Litz, Natalie Marie; Mayfield, David Jerome, McKees Rocks Mahler, Zachary; Pascuzzi, Julie, Clifton Forge, VA Mahoney, Megan Theresa; Enoch, Ryan Matthew, Pittsburgh Martin, William Harry; Iwanonkiw, Marianne, Pittsburgh Matthews, Andrew Joseph; Powers, Justina Marie, Pittsburgh McElhaney, Marissa Marie; Bishop, Carl William, Woodbury, CT Mellon, Gregory Brent; He, Bing, Pittsburgh Mercer, Andrew James; Miles, Brittany Lee, Pittsburgh Meyers, Julienne; Taglieri, Anthony, Pittsburgh Mezhinsky, Constantine Michael; Sekelik, Krista Ann, Pittsburgh Moses, Lee Erica; Glovick, Samuel James, Pittsburgh Nee, Jonathan Patrick; Geisler, Anna Christine, Bethel Park Olsakovsky, Tammy Ann; Tokarsky, Timothy Allen, North Versailles Overbaugh, Elizabeth Marie; Warner, Jeffrey Lyle, Pittsburgh Palamides, Cristina Laura; McGinn, Jason Michael, Glenshaw Parmar, Karan Singh, Monroeville; Adhikari, Jayati, Waltham, MA Paschall, David Lee, New Brighton; Dudley, Buena Renae, Beaver Falls Paul, Kim Lorraine; Weston, Harry Richard, Cheswick Plazek, Emily Anne, Pittsburgh; Schwartz, Eric Michael, Bloomington, IN Powell, Alexander Aaron, Pittsburgh; Kushnar, Sarah Kathryn, Smock Pusatere, Heather Lynn; Boone, Cameron Joseph, Pittsburgh Riordan, Amanda Rae; Tomnay, Bryan Ronald, Pittsburgh Rorick, Joshua Earl; Boyd, Emily Anne, Pittsburgh Russell, James Michael; Bucci, Audrey Mae, Pittsburgh Sauers, Brianne Lynne; Wentz II, John Anthony, Pittsburgh Sawyer, Olivia Jean; Verstreate, Mark David, Pittsburgh Smith, Melanie; Chatterjee, Abir, Pittsburgh Streiff, Joseph Gregory, Glenshaw; Saganis, Aleah Zoe, New Kensington Suss, Nicole Kristen; Kubiczki, Jeffrey Michael, Pittsburgh Taylor, Elissa Marie, Presto; Moore Jr., Michael Anthony, West Homestead Veroli, Maria Victoria; Bonilla, Braulio, Pittsburgh Walter, James Adam; Gaitaniella, Angela Marie, Pittsburgh Walton Jr., Robert Edward; Septak, Michelle Lyn, Bethel Park Wang, Tracy Yuh; Eng, Alexander Geoffrey, Pittsburgh Williams, Shaniel Janique; Parrish Jr., David James, Pittsburgh Williams, Jordan Richard, Zelienople; Macioce, Jane Lee, Coraopolis Wolfendale, Steven; Koch, Mallory, Pittsburgh Wood, Heather Ann; Enos, Ryan, Pittsburgh Wyke, Amy C, Munhall; Nikithser, Brice Michael, Wexford Yowler, Chad; Swope, Amber Rose, Pittsburgh Zangaro, Cara E; Keffer, Adam, Allison Park
↧
REQUEST FOR PROPOSALS THE SHAL...
REQUEST FOR PROPOSALS The Shaler Area School District is soliciting bids for a VEHICLE, and STORM DRAIN IMPROVEMENTS at Shaler Area High School. Sealed bids due back to Shaler Area School District, 1660 Butler Plank Road, Glenshaw, PA, 15116, attention John Kaib, on or before 1:00 p.m. on June 14, 2019 Bid documents may be obtained by contacting the Buildings & Grounds Office at coylek@sasd.k12.pa.us. Shaler Area School District reserves the right to accept or reject any or all proposals and to make the award in the best interest of the School District in accordance with law. SHERRI LUDWIG Board Secretary
↧
↧
NOTICE IS HEREBY GIVEN BY EAST...
Notice is hereby given by East Pittsburgh Economic Development Corporation, a Pennsylvania nonprofit corporation, that said corporation is winding up its affairs in the manner prescribed by section 5975 of the Nonprofit Corporation Law of 1988, so that its corporate existence shall cease upon the filing of Articles of Dissolution in the Department of State of the Commonwealth of Pennsylvania.
↧
NOTICE OF ACTION IN MORTGAGE F...
NOTICE OF ACTION IN MORTGAGE FORECLOSURE IN THE COURT OF COMMON PLEAS OF ALLEGHENY COUNTY, PENNSYLVANIA CIVIL ACTION LAW COURT OF COMMON PLEAS CIVIL DIVISION ALLEGHENY COUNTY No. MG-19-000483 WELLS FARGO BANK, N.A., Plaintiff vs. TIMOTHY H. MONAHAN, in his capacity as Heir of DAVID H. MONAHAN, Deceased; UNKNOWN HEIRS, SUCCESSORS, ASSIGNS, AND ALL PERSONS, FIRMS, OR ASSOCIATIONS CLAIMING RIGHT, TITLE OR INTEREST FROM OR UNDER DAVID H. MONAHAN, DECEASED, Defendants NOTICE To UNKNOWN HEIRS, SUCCESSORS, ASSIGNS, AND ALL PERSONS, FIRMS, OR ASSOCIATIONS CLAIMING RIGHT, TITLE OR INTEREST FROM OR UNDER DAVID H. MONAHAN, DECEASED You are hereby notified that on April 23, 2019, Plaintiff, WELLS FARGO BANK, N.A., filed a Mortgage Foreclosure Complaint endorsed with a Notice to Defend, against you in the Court of Common Pleas of ALLEGHENY County Pennsylvania, docketed to No. MG-19-000483. Wherein Plaintiff seeks to foreclose on the mortgage secured on your property located at 4016 BAKERSTOWN CULMERVILLE ROAD, A/K/A 4016 BAKERSTOWN RD, GIBSONIA, PA 15044 whereupon your property would be sold by the Sheriff of ALLEGHENY County. You are hereby notified to plead to the above referenced Complaint on or before 20 days from the date of this publication or a Judgment will be entered against you. NOTICE If you wish to defend, you must enter a written appearance personally or by attorney and file your defenses or objections in writing with the court. You are warned that if you fail to do so the case may proceed without you and a judgment may be entered against you without further notice for the relief requested by the plaintiff. You may lose money or property or other rights important to you. YOU SHOULD TAKE THIS NOTICE TO YOUR LAWYER AT ONCE. IF YOU DO NOT HAVE A LAWYER, GO TO OR TELEPHONE THE OFFICE SET FORTH BELOW. THIS OFFICE CAN PROVIDE YOU WITH INFORMATION ABOUT HIRING A LAWYER. IF YOU CANNOT AFFORD TO HIRE A LAWYER, THIS OFFICE MAY BE ABLE TO PROVIDE YOU WITH INFORMATION ABOUT AGENCIES THAT MAY OFFER LEGAL SERVICES TO ELIGIBLE PERSONS AT A REDUCED FEE OR NO FEE. Lawyer Referral Service Lawyer Referral Service Allegheny County Bar Association 400 Koppers Building 436 7th Avenue, 3rd Floor Pittsburgh, PA 15219 Telephone (412) 261-5555
↧
OFFICIAL MUNICIPALITY OF BETHE...
OFFICIAL MUNICIPALITY OF BETHEL PARK PUBLIC NOTICE The Bethel Park Municipal Council will consider the following ordinance at their Regular Meeting to be held on Monday, June 10, 2019 at 7:30 PM in the Bethel Park Municipal Building, 5100 West Library Avenue, Bethel Park, PA. Council will consider the following: AN ORDINANCE OF THE MUNICIPALITY OF BETHEL PARK, ALLEGHENY COUNTY, COMMONWEALTH OF PENNSYLVANIA, INITIATING A REFERENDUM TO AMEND THE HOME RULE CHARTER OF THE MUNICIPALITY OF BETHEL PARK TO REMOVE PROVISIONS REQUIRING THE MUNICIPAL PLANNER AND THE MUNICIPAL FINANCIAL OFFICER TO BE BECOME RESIDENTS OF THE MUNICIPALITY OF BETHEL PARK WITHIN ONE YEAR OF APPOINTMENT A copy of the full text of this ordinance may be examined by any citizen weekdays between the hours of 8:00 a.m. and 4:30 p.m. at the Bethel Park Municipal Building, 5100 West Library Avenue. Chief Timothy O'Connor, Acting Manager
↧
LEGAL NOTICE MUNICIPALITY OF B...
LEGAL NOTICE Municipality of Bethel Park Allegheny County, Pennsylvania NOTICE OF CONSIDERATION OF ORDINANCE ACCEPTING A LOAN OF $1,367,000.00 TO CONSTRUCT THREE STORM WATER MANAGEMENT PROJECTS SERVING AREAS DOWNSTREAM OF OAK TREE PARK, LOGAN ROAD PONDS AND BIRCH TREE PARK NOTICE IS HEREBY GIVEN that on Monday, June 10, 2019 , at 7:30 P.M., at the Bethel Park Municipal Building, Council Chambers, 5100 W. Library Avenue, Bethel Park, PA 15102, Pennsylvania, the officers of the Municipality of Bethel Park, Allegheny County, Pennsylvania, will act on an ordinance (of which this notice is the summary) authorizing the issuance of an awarding of its $1,367,000.00 principal amount, general obligation Note, at a private sale. If enacted, the ordinance will award the Note to the purchaser thereof, approve the form of the Note, fix the rate of interest to be paid, pledge the full faith and credit of the local government unit for the payment thereof, create a sinking fund and authorize the proper officers to take the necessary steps to issue the Note. The funds to be obtained from the borrowing will be used for the following purpose: Construction of three storm water management projects serving areas downstream of Oak Tree Park, Logan Road Ponds and Birch Tree Park. A copy of the full text of the proposed ordinance may be examined by any citizen in the offices of the Municipality of Bethel Park, at 5100 W. Library Avenue, Bethel Park, PA 15102, on any business day (except Saturdays and Sundays) between the hours of 8 A.M. and 4:30 P.M., prevailing time. MUNICIPALITY OF BETHEL PARK Chief Timothy O'Connor Acting Municipal Manager
↧
↧
ALLEGHENY COUNTY COURT OF COMM...
Allegheny County Court of Common Pleas Number: GD-19-007128 Notice of Action in Mortgage Foreclosure Nationstar Mortgage LLC d/b/a Mr. Cooper, Plaintiff v. Unknown Surviving Heirs of Dyann E. Carroll, Defendant TO: Unknown Surviving Heirs of Dyann E. Carroll. Premises subject to foreclosure: 939 Middle Road, Pittsburgh, Pennsylvania 15223. NOTICE: If you wish to defend, you must enter a written appearance personally or by attorney and file your defenses or objections in writing with the court. You are warned that if you fail to do so the case may proceed without you and a judgment may be entered against you without further notice for the relief requested by the Plaintiff. You may lose money or property or other rights important to you. You should take this notice to your lawyer at once. If you do not have a lawyer, go to or telephone the office set forth below. This office can provide you with information about hiring a lawyer. If you cannot afford to hire a lawyer, this office may be able to provide you with information about agencies that may offer legal services to eligible persons at a reduced fee or no fee. Lawyer Referral Service, Allegheny County Bar Association, 400 Koppers Building, 3rd Floor, 436 Seventh Avenue, Pittsburgh, Pennsylvania 15219, (412) 261-5555. McCabe, Weisberg & Conway, LLC, Attorneys for Plaintiff, 123 S. Broad St., Ste. 1400, Philadelphia., PA 19109, 215-790-1010
↧
ADVERTISEMENT FOR BIDS SEALED ...
ADVERTISEMENT FOR BIDS Sealed proposals will be received by the Borough of White Oak, 2280 Lincoln Way, White Oak, PA 15131 on June 17, 2019 until 11:00 AM. Bids will be publicly opened and read immediately thereafter for the 2019 STREET PAVING PROGRAM consisting of the following approximate asphalt paving quantities: 18,200 SY 4 milling; 18,200 SY 1-1/2 9.5 mm fine grade superpave wearing course; 2,500 tons 19 mm binder leveling course; 9,385 LF curb backfill; 25 inlets; 1,000 LF of 15 HDPE storm pipe; 1,800 SY base repair; and curb & gutter sealing. Plans, Specifications, Form of Contract, Instructions to Bidders and Proposal Forms may be obtained at Senate Engineering Company, U-PARC, 420 William Pitt Way, Pittsburgh, PA 15238 (412) 826-5454. A non-refundable deposit of $35.00 for reproduction and binding of the specifications and plans will be required. Proposal must be upon the forms furnished by the Borough of White Oak and must be accompanied by a certified check or bid bond, in the form attached to the Contract Documents, in the amount of 10% of the Bid, made payable to the Borough of White Oak. All envelopes containing Bid proposal shall be sealed and clearly marked "2019 STREET PAVING PROGRAM. The Borough of White Oak reserves the right to waive any informalities or to reject any or all proposals, for any reason whatsoever.
↧
CITY OF PITTSBURGH OFFICE OF M...
CITY OF PITTSBURGH Office of Management & Budget ADVERTISEMENT Separate and sealed bids will be received electronically starting at 9:00am EST on Friday, May 31, 2019 and will be publicly opened as designated in the individual solicitation in the presence of the Assistant Director, Bureau of Procurement or his/her designee, in Room 502, City-County Building, 414 Grant Street, Pittsburgh, PA 15219: FIFB19000356 Roofing Repair & Maintenance (CD) Information on electronic solicitations may be obtained at the City of Pittsburgh website at http://purchasing.pittsburghpa.gov. All bids must be submitted via the above noted website and all required documents must be provided or the bid will be considered non-responsive. For individual projects solicited under these contracts, bids must be accompanied by a bid bond in the amount of five percent (5%) of the bid for the project under consideration. Said bond shall be duly and legally executed with a surety or trust company which has complied with city ordinances/resolutions relating thereto. Wages paid on this project shall not be less than the minimum wages determined by the U.S. Department of Labor as set forth in the contract documents. The contractor will be required to comply with all applicable Equal Employment Opportunity requirements for Federally Assisted construction contracts. The contractor must assure that employees and applicants for employment are not discriminated against because of their race, color, religion, sex or national origin. Attention is called to Executive Order 11246, to Section 3 of the Housing and Urban Development Act of 1968, 12 U.S.C. 1701U, and to the Section 3 Clause and Regulations set forth in 24 CFR, Part 135. The Contractor will be required to comply with the following laws, rules and regulations: All provisions of US Executive Order 11246 of September 24, 1965, as amended by US Executive Order 11375 and as supplemented in US Department of Labor Regulations (41 CFR, Part 60), and of the rules, regulations, and relevant orders of the US Secretary of Labor. Contractor shall comply with all applicable standards, orders, or requirements issued of the Clean Air Act (42 USC 1857 et. seq.), Section 508 of the Clean Water Act (33 USC 1368), Executive Order 11738, and Environmental Protection Agency regulations (40 CFR, Part 15). Contractor shall comply with the Davis-Bacon Act the Davis-Bacon Act (40 U.S.C. 276a to 276a-7) as supplemented by Department of Labor regulations (29 CFR part 5). Procedures for compliance's to these acts shall be as follows: All specifications for construction contracts and subcontracts will contain the prevailing wage rates (as enclosed in this bid package) as determined by the Secretary of Labor in accordance with the Davis-Bacon Act, as amended (40 U.S.C. 276-a to 276-C-5) and provision that overtime compensation will be paid in accordance with the Contract Work Hours and Safety Standards Act Regulations (29 CFR, Parts 5 and 1926). The contract provisions shall require that these standards be met. Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity (Executive Order 11246): Bidder's attention is called to the Equal Opportunity Clause and the Standard Federal Equal Employment Specifications set forth in 41 CFR Public Contracts and Property Management Part 60-4.3 Equal Opportunity Clauses. The goals and timetables for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area are as follows: Goals for minority participation: 18% Goals for female participation: 7% These goals are applicable to all contractors' construction work (whether or not it is Federal or federally assisted) performed in the covered area. As used in this notice, and in the contract resulting from this solicitation, the covered area is Pittsburgh SMSA (Allegheny, Washington, Beaver and Westmoreland counties). The contractor shall comply with Title VI of the Civil Rights Act of 1964 and 1988, as amended, Section 109 of the Community Development Act of 1974, with Executive Order 11625 (Minority Business Enterprise) and Executive Order 12138 (Women's Business Enterprise). The bidders will be required to submit the package of certifications included with the contract documents relating to Equal Employment Opportunity. The City reserves the right to withhold the award of contract for a period of sixty (60) calendar days after the opening of bids. The City's Office of Management & Budget reserves the right to reject any and all Proposals. Jennifer Olzinger Acting Director Office of Management & Budget
↧
NOTICE IS HEREBY GIVEN THAT AR...
NOTICE is hereby given that Articles of Incorporation were filed with the Department of State of the Commonwealth of Pennsylvania, for a business corporation which has been incorporated under the provisions of the Business Corporation Law of 1988. The name of the corporation is Mugen Press, Inc.
↧
↧
FINAL BUDGET NOTICE NOTICE IS ...
Final Budget Notice NOTICE is given that the Proposed Final Budget for the General Fund of the Chartiers Valley School District for the 2019-2020 fiscal year in its most recent form is available for public inspection at the school district offices, 2030 Swallow Hill Rd. Pittsburgh, Pennsylvania 15220, and will be presented for adoption as a Final Budget at a school board meeting to be held in the district assembly room of the District's Administrative Offices, 2030 Swallow Hill Rd. Pittsburgh, PA 15220, at 6:30p.m. on June 25, 2019. The budget may be amended before or after the final adoption. Kimberly Borza Secretary Board of School Directors
↧
IN THE UNITED STATES BANKRUPTC...
IN THE UNITED STATES BANKRUPTCY COURT FOR THE WESTERN DISTRICT OF PENNSYLVANIA IN RE: Penny L. Caswell BANKRUPTCY NUMBER: 17-21249-JAD NOTICE OF SALE TO CREDITORS AND OTHER PARTIES IN INTEREST Notice is hereby given that Lauren M. Lamb, Attorney for the Debtor, has filed a Motion to Sell Real Property Free and Clear of all Liens, Judgments and Encumbrances. The Debtor, Penny L. Caswell, has received an offer of $120,000.00 for the Debtor's real property being known as 2657 Quail Hill Drive Pittsburgh, PA 15241 in Allegheny County free and clear of all liens and encumbrances. A hearing will be held in Courtroom D, 54th Floor, U.S. Steel Tower, 600 Grant Street, Pittsburgh, PA 15219 on June 26, 2019 at 11:00 AM for the purpose of passing on said Motion when and where all objections will be heard, when and where the public is invited; and when and where higher and better offers will be accepted. Additional information is available at the office of the debtor's attorney, Lauren M. Lamb, Esquire, Steidl and Steinberg, Suite 2830 Gulf Tower, 707 Grant Street, Pittsburgh, PA 15219, (412) 391-8000.
↧
NOTICE OF SCHEDULED QUARTERLY ...
Notice of Scheduled Quarterly Meeting (Pursuant to the Act of July 19, 1994, P.L. #386, 65 P.S. 261) THE CITY OF PITTSBURGH-EQUIPMENT LEASING AUTHORITY BOARD MEETING SHALL BE HELD ON: Thursday, June 27, 2019 2:00 P.M. CITY-COUNTY BUILDING, ROOM 510 (CONFERENCE ROOM) PITTSBURGH, PA 15219
↧